ARMORWORKS
TERMS AND CONDITIONS

1. FORMATION OF CONTRACT.

This proposed contract is Buyer’s offer to purchase the goods and services (Goods) described in this offer. Acceptance is strictly limited to the terms and conditions in this offer. Unless specifically agreed to in writing by Buyer’s Authorized Procurement Representative, Buyer objects to, and is not bound by, any term or condition that differs from or adds to this offer. Seller’s commencement of performance or acceptance of this offer in any manner shall conclusively evidence of this offer as written.


2. SCHEDULE

a. Seller shall strictly adhere to shipment or delivery schedules specified in this contract. In the event of any anticipated or actual delay, including but not limited to delays attributed to labor disputes, Seller shall: (i) promptly notify Buyer in writing of the reason for the delay and the actions being taken to overcome or minimize the delay; (ii) provide Buyer with a written recovery schedule; and (iii) if request by Buyer, ship via air or other expedited routing to avoid or minimize delay to the maximum extent possible, unless Seller is excused from prompt performance as provided in the “ Force Majeure” article of this contract. The added premium transportation costs are to be borne by Seller.

b. Seller shall not deliver Goods prior to the scheduled delivery dates unless authorized by Buyer.

c. Buyer shall, at no additional cost, retain goods furnished in excess of the specified quantity or in excess of any allowable overage unless, within 45 days of shipment, Seller request return of such excess. In the event of such request, Seller shall reimburse Buyer for reasonable costs associated with storage and return of the excess. If Goods are manufactured with reference to Buyer’s proprietary information or materials, Seller aggress that, pursuant to the “Confidential, Proprietary and trade Secrets Information and Materials” article if this contract, it will not sell or offer such goods for sale to anyone other than Buyer without Buyer’s prior written consent.


3. PACKING AND SHIPPING

a. Seller shall pack the Goods to prevent damage and deterioration Seller shall comply with carrier tariffs. Unless this contract specifies otherwise, the price includes shipping charges for the Goods sold F.O.B. destination. Unless otherwise specified in this contract, Goods sold F.O.B. place of shipment shall be forwarded collect. Seller shall make no declaration concerning the value of the Goods shipped except on Goods where tariff rating is dependant upon released or declared value. In such event, Seller shall release or declare such value at the maximum value within lowest rating. Buyer may charge seller for damage to or deterioration of any Goods resulting from improper packaging or packaging.

b. Unless this contract specifies otherwise, Seller will ship the Goods in accordance with the following instructions:

(i) Shipments by Seller or its subcontractors must include packaging sheet containing Buyer’s contract number, line item number, description and quantity of Goods shipped, part number or size, if applicable, and appropriate evidence of inspections. A shipment containing hazardous and no hazardous materials must have separate packing sheets for the hazardous and no hazardous materials. Seller shall not include vermiculite or other hazardous substance is any packaging material included with the Goods. Items shipped on the same day will be consolidated on one billing of landing on one bill of landing of air bill unless Buyer’s Authorized Procurement Representative authorizes otherwise. The shipping documents will describe the material according to the applicable classification and/of tariff. The total number of shipping containers will be referenced an all shipping documents. Originals off all Government bills of lading will be surrendered to the origin carrier at the time of shipment.

(ii) Seller will not insure any FOB origin shipment unless authorized by Buyer.

(iii) Seller will label each shipping container with the contract number and the number on each container represents of the total number being shipped (e.g. box 1 of 2, box 2 of 2)

(iv) Buyer will select the carrier and mode of transportation for all shipments where freight is costs are charged to Buyer.

(v) Seller will include copies of documentation supporting prepaid freight charges (e.g., carrier invoices or UPS shipping log/manifest), if any with its invoices.

(vi) If seller is unable to comply with the shipping instructions in this contract, Seller will contact Buyer’s Traffic Management Department referenced elsewhere in this contract or Buyer’s Authorized Procurement Representative.


4. QUALITY CONTROL.

Seller shall established and maintain a quality controls sys tem acceptable to Buyer for the goods purchased under this contract. Seller shall permit Buyer to review procedures, practices, and related documents to determine such acceptability. Seller shall have a continuing obligation to promptly notify Buyer of any violation or deviation from sellers approved inspection/quality control system and to advise Buyer of the quantity and specific identity if ant Goods delivered to buyer the period of any such violation or deviation.


5. SELLER’S NOTICE OF DISCREPANCIES.

Seller shall notify Buyer in writing when discrepancies in Seller’s process or Goods are discovered or suspected regarding Goods delivered or to be under this contract.


6. INSPECTION

a. At no additional cost to Buyer, Goods shall be subject to inspection, surveillance and test at reasonable times and places, including Seller’s subcontractors’ locations. Buyer shall perform inspections, surveillance and tests so as not to unduly delay the work.

b. Seller shall maintain an inspection system acceptable to Buyer for the Goods purchased under this contract.

c. If Buyer performs an inspection or test in the premises if Seller or its subcontractors, Seller shall furnish, and require its subcontractors to furnish, with out additional charge, reasonable facilities and assistance for the safe and convenient performance of these duties.


7. ACCEPTANCE AND REJECTION

a. Buyer shall accept the Goods of give seller notice of rejection or revocation of acceptance (“rejection” herin), notwithstanding in payment, prior test or inspection, or passage of title. No inspection, test, delay or failure to inspect or test failure to discover any defect or other nonconformance shall relive Seller of any obligations under this contract or impair and rights or remedies of Buyer.

b. If Seller delivered non-conforming Goods, Buyer may at its option and at Seller’s expense (i) return the goods for credit of refund; (ii) require Seller to promptly correct or replace the Goods; (iii) correct the Goods; or (iv) obtain replacement Goods from another source.

c. Seller shall not redeliver corrected Goods or rejected Goods without disclosing the former rejection or requirement for correction. Seller shall disclose and corrective action taken. Repair, replacement and other correction and redelivery shall be completed within the original delivery schedule or such later time as Buyer’s Authorized Procurement Representative may reasonably direct.

d. All costs and expenses and loss of value incurred as a result of or in connection with connection with nonconformance and repair, replacement or other correction may be recovered from Seller by equitable price reduction or credit against any amount that may be owed to Seller under this contract otherwise.


8. WARRANTY

a. Seller warrants that all Goods furnished under this contract shall conform to all specifications and requirements of this contract and shall be free from defects in material and workmanship. To the extent Goods are not manufactured pursuant to detailed design and specifications furnished by Buyer, The Goods shall be free from design and specification defects. This warranty shall survive inspection, test and acceptance of, and payment for, the Goods this warranty shall run to Buyer and its successors, assigns and customers. Such warranty shall begin after Buyer’s final acceptance. Buyer may, at is option, either (i) return for credit or refund, or (ii) require prompt correction or replacement of the defective non-conforming Goods. Return to Seller of defective or non-conforming Goods and redelivery to Buyer of corrected to replaced Goods shall be at s\Seller’s expense. Goods required to be corrected or replaced shall be subject to this article and the “Inspection” article of this contract in the same manner and to the same extent as Goods originally delivered under this contract, but only as to the corrected or replace part or parts thereof. Even if the parties disagree about the existence of a breach of this warranty, Seller shall promptly comply with Buyer’s directions to: (i) repair, rework or replace the Goods, or (ii) furnish and materials or parts and installation instructions required to successfully correct the defect or nonconformance. If the parties later determine that Seller sis not breach this warranty, the parties shall equitably adjust the contract price.

b. Seller warrants that any hardware, software and firmware Goods delivered under this contract shall be abler to accurately process date/time data (including, but not limited to, calculating, comparing and sequencing) from, into and between the twentieth and twenty-first centuries, and the years 1999 and 2000 and leap year calculations to the extent that other information technology, used in combination with the information technology being acquired, properly exchanges date/time data with it. The duration of this warranty and the remedies available to Buyer for breach of this warranty shall be defined in, and subject to, the other warranties contained in this contract, provided that not with\standing and provisions to the contrary is such warranties, the remedies available to Buyer under this warranty shall include repair or replacement of any non-compliant Goods discovered and made known to Seller in writing. Nothing I this warranty shall be construed to limit and rights or remedies Buyer may otherwise have e under this contract with respect to defects other that year 2000 performance.


9. TAXES.

Unless this contract specifies otherwise, the price of this contract includes, and Seller is liable for and shall pay, all taxes, impositions, charges and exactions imposed on or measured by this contract except for applicable sales and use taxes that are separately stated on Seller’s invoice. Prices shall include and taxes, impositions, charges or exactions for witch Buyer has furnished a valid exemption.


10. INVOICES AND PAYMENT.

Unless otherwise authorized by Buyer’s Authorized Procurement Representative, Seller shall issue a separate original invoice for each delivery that shall include Buyer’s Contract number and line item number. Seller shall forward its invoice to the address specified elsewhere in this contract. Unless freight or other charges are itemized, Buyer may take any offered discount on the full; amount of the invoice. Payment due date, including discount periods, shall be computed from the later of the scheduled delivery date, the actual delivery date or the date of receipt if a correct invoice. Payment shall be deemed made on the date Buyer’s check is mailed or payment is otherwise tendered. Seller shall promptly repay Buyer amounts paid in excess of amounts due Seller.


11. CHANGES

a. Buyer’s Authorized Procurement Representative may , with oust notice to sureties and in writing , direct changes with in general scope of this contract in any of the following: (i) technical retirements and descriptions, specifications, statement of work, drawings or design ; (ii) shipment or packaging methods ;(ii) place of delivery , inspection or acceptance; (iv) reasonable adjustments in quantities id delivery schedules or both; (v) amount of Buyer-furnished property; and if this contract includes services (vi) description of services to be preformed ; (vii) time of performance (e.g. hours of the day, days of the week); (viii) place of performance, and (ix) terms and conditions of this contract required to need Buyer’s obligations under Governments prime contracts or subcontracts. Seller shall comply with such directions.

b. If such change increases or decrease the cost or time requirement to perform this contract, Buyer and Seller shall negotiate and equitable adjustment in the price in the schedule, or both, to reflect the increase or decrees. Buyer shall modify this contract in writing accordingly. Unless otherwise agreed in writing, Seller must assert and claim for adjustment to Buyer’s Authorized representative ion writing with in 25 days and deliver a fully supported proposal to Buyer’s Authorized Procurement Representative with in 60 days after Seller’s receipt of such direction. Buyer may, at its sole discretion, consider any claim regardless if when asserted. If Seller’s proposal includes the cost of property made obsolete or excess by the change, Buyer may direct the disposition of the property. Buyer may examine Seller’s pertinent books and records to verify the amount of Seller’s claim. Failure of the parties to agree upon any adjustment shall not excuse Seller from performing in accordance with Buyer’s direction.

c. If Seller considers that Buyer’s conduct constitutes a change, Seller shall notify buyer’s Authorized Procurement Representative immediately in writing as to the nature of such conduct and its effect upon seller’s performance. Pending direction from Buyer’s Authorized Procurement Representative, Seller shall take no action to implement any such change.


12. DISPUTES.

Any dispute that arises under or is related to this contract that cannot be settled by mutual agreement of the parties may be decided by court of competent jurisdiction. Pending final resolution of any dispute, Seller shall proceed with the performance of this contract according to the Buyer’s instructions so as long as Buyer continues to pay amounts not in dispute.


13. FORCE MAJEURE.

Seller shall not be liable for excess reprocurement costs pursuant to the “Cancellation for Default” article of this contract, incurred by Buyer because of any failure to perform this contract under its terms if the failure arises from causes beyond the control and without the fault or negligence of Seller. Examples of these causes (a) acts of God of the public enemy, (b) acts of the government in either its sovereign or contractual capacity, (c) Fires, (d) floods, (e) epidemics, (f) quarantine restrictions, (g) strikes, (h) freight embargoes and (i) unusually severe weather. In each instance, the failure to perform must be beyond the control and with out fault or negligence of Seller. If the delay is caused by delay of a subcontractor of Seller and if such delay arises out of cause beyond the reasonable control of both, and if such delay is without the fault or negligence of either, Seller shall not be liable for excess dost unless the Goods or services to be furnished by the subcontractor were obtainable from other sources in sufficient time to permit Seller to meet the required delivery schedules. Seller shall notify Buyer in writing within 10 days after beginning of any such cause.


14. TERMINATION FOR CONVENIENCE.

Buyer may terminate all or part of this contract, effective as of the date specified by the Buyer, in accordance with the provisions of Federal Acquisitions Regulation (“FAR”) 52.249-2 (Sep96), Termination for Convenience of the government (Fixed Price),” which provisions except for subparagraphs (d) and (i), are incorporated herein reference . the terms “Government” and “Contracting officer” shall mean “Buyer”, “Contractor” shall mean “Seller”, and the phrase “1 year” is delayed each place it occurs and “six months” is substitute in its place. The time for requesting and equitable adjustment under subparagraphs (1) is reduced to 45 days. Settlements and payments under this article may be subject to approval by the Contracting Office and the Settlement Review Board.


15. CANCELLATION FOR DEFAULT
 
a. Buyer may , by written notice to Seller, Cancel all or part of this contract if (i) Seller fails to deliver the Goods with in the time specified by this contract or any written extension; (ii) Seller fails to perform and other provisions of this contract or fails to make progress, so as to endanger performance of this contract, and in either of these two circumstances, does not cure the failu8re with in 10 days after receipt of notice from Buyer specifying the failure; or (iii) in the event of Seller’s suspension of business, insolvency, appointment of a receiver for Seller’s property or business , or any assignment, reorganization or arrangement by Seller for the benefit of it’s creditors.

b. Seller shall continue work not canceled. If Buyer cancels all or part of this contract, Seller shall be liable for Buyer’s excess re-procurement costs.

c. Buyer may require Seller to transfer title and deliver to Buyer, any (i) completed Goods, and (ii) any partially completed Goods and materials, parts , tools, dies, jigs, fixtures, plans, drawings, information, and contract rights (collectively, “Manufactured Materials”) that seller has specifically produced or acquired for the cancels portion o this contract. Upon direction from Buyer, Seller shall also protect and preserve property in its possession in which Buyer or its Customer has interest.

d. Buyer shall pay the contract price for Goods accepted. Payment fro Manufacturing Materials accepted by Buyer and for the protection and preservation of property shall be at a price determined in accordance with the “Termination for Convenience” article of this contract, except Seller shall not be entitled to profit. Buyer may withhold any amount due under this contract any sum Buyer determines to be necessary to protect Buyer or Buyer’s customer against loss because of outstanding liens or claims of former lien holders.

e. If, after cancellation, it is determined that Seller was not in default the rights and remedies of the parties shall be as if the contact had been terminated according to the “Termination of Convenience” article in this contract.


16. ASSIGNMENT, DELEGATION AND SUBCONTRACTING.

Seller shall not assign any of its rights or interest in this contract or subcontract all or substantially all of its performance of this contract, with out Buyer’s prior written consent. Seller shall not delegate any of its duties or obligations under this contract. Seller may assign its right to monies due or to become due. No assignment , delegation or subcontracting by Seller, with or with out Buyer’s consent, shall relieve Seller of any of its obligations under this contract or prejudice any of Buyer’s right against Seller whether arising before or after the date of any assignment. This article does not limit Seller’s ability to purchase standard commercial supplies or raw materials.


17. PUBLICITY.

Without Buyer’s prior written approval, Seller shall not, and shall require that its subcontractors at any tier shall not, release and publicity, advertisement, news release or denial or confirmation of same regarding this contract or the Goods or program to which it pertains. Seller shall be liable to Buyer for any breach of such obligation by any subcontractor.


18. BUYERS PROPERTY.

Seller shall clearly mark, maintain and inventory of, and keep segregated or identifiable all of Buyer’s property and all property to which Buyer acquires an interest by virtue of this contract. Seller assumes all risk of loss, destruction or damage of such property while in Seller’s possession, custody control, including and transfer to Seller’s subcontractors. Upon request, Seller shall provide Buyer with adequate proof of insurance against such risk of loss. Seller shall not use such property other than in performance of this contract without Buyer’s prior written consent. Seller shall notify Buyer’s Authorized Procurement Representative if Buyer’s property is lost, damage or destroyed. As directed by Buyer, upon completion, termination or cancellation of this contract, Seller shall deliver such property, to the extent not incorporated in delivered Goods, to Buyer in good condition subject to ordinary wear and tear and normal manufacturing losses. Nothing in this article li9mits seller’s use, in its direction contract with the Government, of property in which the Government has interest.


19. PATENT, TRADEMARK AND COPYRIGHT INDEMNITY.

Seller will indemnify, defend and hold harmless Buyer and its customer from all claims , suits, actions, awards (including, but not limited to awards based on international fees and/or costs), Liabilities, damages, costs and attorney’s fees related to the actual or alleged infringement of any United States or foreign intellectual property right (including, but not limited to, and right in a patent, copyright, industrial design or semiconductor mask work or based on misappropriation or wrongful use of information or documents). and arising out of the manufacture, sale or use of Goods by either Buyer or its customer. Buyer and /or its customer will duly notify Seller of any such claim, suit or action; and Seller will, at its own expense, fully defend such claim, suit, or action on behalf of indemnities. Seller will have no obligation under this article with regard to any infringement arising from (a) Seller’s compliance with formal specifications issued by Buyer where infringement should not be avoided in complying with such specifications or (b) use or sale of Goods in combination with other items when such infringement would not have occurred from the use or sale of those Goods solely for the purpose for which they were designed or sold by Seller. For purpose of this article only, the term Buyer will include The Boeing Company and all Boeing subsidiaries and all officers, agents and employees of Boeing or and Boeing subsidiary.


20. CONFIDENTIAL, PROPRIETARY AND THE TRADE SECRET INFORMATION AND MATERIALS.

Buyer and Seller shall each keep confidential and protect from unauthorized use and disclosure all (a) confidential, proprietary and/or trade secret information; (b) tangible items and software containing, conveying or embodying such information; and (c) tooling identified as being subject to this article and obtained, directly or indirectly , from the other in connection with this contractor other agreement referencing this contract (collectively referring to as “Proprietary Information and Materials”). Buyer and Seller shall each use proprietary information and Materials of the other only in the performance of and for the purpose in this contract. However, despite any other obligations or restrictions imposed by this article. Buyer shall have the right to use, disclose and reproduce Seller’s Propriety Information and Materials, and make derivative works thereof, for the purpose of testing, certification, use, sale or support of any Goods delivered under this contract or any other agreement referencing this contract. Any such use, disclosure, reproduction or derivative work by Buyer shall, whenever appropriate, include a restrictive legend suitable for the particular circumstances. The restrictions on disclosure or use of Proprietary Information and Materials by Seller shall apply to all materials derived by Seller or others from Buyer’s Proprietary Information and Materials. Upon Buyer’s request at any time, and in any event upon the completion, termination or cancellation id this contract, Seller shall return to Buyer all of Buyer’s Proprietary Information and Materials and all materials derived there from, unless specifically directed otherwise in writing by Buyer. Seller shall not, without the prior written authorization of Buyer, sell or otherwise dispose of (as scrap or otherwise) any parts or other material containing, conveying, embodying or make in accordance with or by reference to any Proprietary Information of Buyer. Prior to disposing of such parts or other materials as scrap, Seller shall render them unusable. Buyer shall have the right to audit Seller’s compliance with this article. Seller may disclose Proprietary information and Materials of buyer to its subcontractors as required for the performance of this contract, provided that each subcontractor first agrees in writing to the same obligations imposed upon Seller under this article relating to Proprietary Information and Material. Seller shall be liable to Buyer for any breach of such obligations by such subcontractor. The provisions of this article are effective in lieu of any restrictive legends or notices applied to Proprietary Information and Materials. The provisions of this article shall survive the performance, completion, termination or cancellation of this contract.


21. RECORDS AND AUDITS.

Seller shall retain all record and documents pertaining to the Goods for a period of no less than three years after final payment. Such records and documents shall date back to the time this contract was issued and shall include without limitation, catalogs, price lists, invoices and inventory records for purpose of verification of prices at rates charged by Seller for Goods procured by Buyer. Buyer shall have the eight to examine , reproduce and audit all such records related to pricing and performance to evaluate that accuracy, completeness and currency of cost and pricing data submitted with Seller’s bid or offer to sell; and related to “Changes,” “ Termination for Convenience” or Cancellation for Default” articles of this contract.


22. RIGHTS OF BUYER’S CUSTOMERS AND REGULATORS TO PERFORM INSPECTION, SURVEILLANCE AND TESTING.

Buyer’s rights to perform inspections, surveillance and tests and to review procedures, practices, processes and related documents related to quality assurance, quality control, flight safety and configuration control shall extend to the customer’s of BUYER that are departments, agencies or instrumentalities of the United States GOVERNMENT and to the United States Government Federal Aviation Administration and any successor agency or instrumentality of the United States Government. Buyer may also, at Buyer’s option, by prior written notice from Buyer’s Authorized Procurement Representative, extend such rights to other customers of Buyer and to agencies or Buyer’s Authorized Procurement Representative, extend such rights to the other customers f Buyer and to agencies or instrumentalities of foreign governments equivalent in purpose to the Federal Aviation Administration, Seller shall cooperate with any such United States Government-directed or Buyer-directed inspections , surveillance, test or review with out additional charge to Buyer. Nothing in this contract shall be interpreted to limit United States Government access to Seller’s facilities pursuant to law or regulation.


23. GRATUITIES.

Seller warrants that neither it nor any of its employees, agents, and representatives have offered or given, or will
offer, any gratuities to Buyer’s employees, agents or representatives for the purpose of securing favor treatment under this contract.


24. OFFSET CREDITS

a. To the exclusion of all others, Buyer or its assignees shall be entitled to all industrial benefits or offset credits which might result from this contract. Seller shall provide documentation or information that Buyer or its assignees may reasonably request to substantiate claims for industrial benefit or offset credits.

b. Seller agrees to use reasonable efforts to identify the foreign content of goods that Seller either produces itself or procures from subcontractors for work directly related to this contract. Promptly after selection of a non-U.S. subcontractor for work under this contract, Seller shall notify Buyer of the name, address, subcontract point of contact (including telephone number) and dollar value of the subcontract.


25. UTILIZATION OF SMALL BUSINESS CONCERNS.

Seller agrees to actively seek out and provide that maximum practicable opportunities for small businesses, small disadvantage businesses, women-owned small businesses, minority business enterprises, historically black colleges and universities and minority institutions, Historically Underutilized Business Zone small business and U.S. concerns and U.S. veteran and Service-Disables Veteran Owned small business concerns to participate in subcontractors Seller awards to the fullest extent consistent with the efficient performance of this contract.


26. RIGHTS AND REMEDIES.

Any failures, delays or forbearance of either party I insisting upon reinforcing any provisions of this contact , or in exercising any rights or remedies under this contract, shall not be constructed as a waiver or relinquishment of any such provisions, rights or remedies ; rather, the same shall remain in full force and effect. Except as otherwise limited in this contract, the right and remedies set forth herein are cumulative and in addition to any other rights or remedies that the parties may have at law or in equity. If any provisions of this contract is or becomes void or unenforceable by law, the remainder shall be valid and enforceable.


27. COMPLIANCE WITH LAWS.

Seller shall comply with all applicable statues and government rules, regulations and orders, including those pertaining to United States Exports Controls.


28. GOVERNING LAW.

This contract shall be governed by and constructed in accordance with the laws of the state of Arizona.


29. GOVERNMENT CLAUSES.

Government clauses applicable to this contract are incorporated herein either by attachment to this document or by some other means of reference.


30. SUSPENSION OF WORK

a. Buyer’s Authorized Procurement Representative may, be written orders, suspended all or part of the work to be preformed under this contract for a period not to exceed 100 days. Within such period of any suspension of work, buyer shall (i) cancel the suspension of work order; (ii) terminate this contract in accordance with the “Termination for Convenience” article of this contract; (iii) cancel this contract in accordance with the “Cancellation for Default” article of this contract; or (iv) extend the stop work period.

b. Seller shall resume work whenever a suspension is cancels. Buyer and Seller shall negotiate an equitable adjustment in the price or schedule or both if (i) this contract is not canceled or terminated; (ii) the suspension results in a change in Seller’s cost of performance or ability to meet the contract delivery schedule; and (iii) Seller submits a claim for adjustment within 20 days after the suspension is canceled.


31. ACCESS TO PLANTS AND PROPERTIES.

Seller shall comply with all the rules and regulations established by Buyer for access to and activities in and premises controlled by Buyer and Buyer’s customer.


32. ENTIRE AGREEMENT.

This contract contains entire agreement of the partied and supersedes any and all prior agreements, understanding and communications between Buyer and Seller related to the subject matter of this contract. No amendment or modification of this contract shall bid either party unless it is in writing and is signed by both Buyer’s Authorized Procurement Representative and an authorized representative of Seller.